               ARMED SERVICES BOARD OF CONTRACT APPEALS

Appeal of --                                  )
                                              )
PROTEC GmbH                                   )      ASBCA No. 61185
                                              )
Under Contract No. W912CM-14-P-0008           )

APPEARANCES FOR THE APPELLANT:                       Paul D. Reinsdorf, Esq.
                                                      Attorney at Law
                                                      Frankfurt/Main, Germany

                                                     Steven J. Kmieciak, Esq.
                                                      Seyfarth Shaw LLP
                                                      Washington, DC

APPEARANCES FOR THE GOVERNMENT:                      Raymond M. Saunders, Esq.
                                                      Army Chief Trial Attorney
                                                     Dana J. Chase, Esq.
                                                      Trial Attorney

                  OPINION BY ADMINISTRATIVE JUDGE SWEET

        This appeal involves a contract between the Regional Contracting Office,
Wiesbaden (government) and appellant PROTEC GmbH (PROTEC) to maintain and
repair equipment at U.S. Army Garrison, Wiesbaden. The government refused to pay
some invoices. PROTEC submitted a claim seeking to have the government pay the
unpaid invoices. The contracting officer (CO) issued a final decision (COFD) denying
that claim, which PROTEC appeals.

        The government argues that it properly refused to pay the unpaid invoices
because, inter alia, 1 PROTEC submitted electronic reports and invoices late, which
prevented the government from verifying that PROTEC properly performed the
billed-for services. PROTEC responds that the government suffered no prejudice from
the late electronic reports and invoices because timely paper reports, the maintenance
schedule, and the contracting officer representative's (COR's) role in arranging
emergency repairs allowed the government to verify performance. PROTEC also
argues that it submitted the invoices late because of delays receiving signed work
certificates from the government and invoices from suppliers.

1
    Because we find that PROTEC' s late submission of reports and invoices justified the
        government's refusal to pay the unpaid invoices, we do not address the
        government's other proffered reasons for not paying the unpaid invoices.
       ·The government properly refused to pay the unpaid invoices because PROTEC
failed to submit timely electronic reports and invoices. The lack of timely electronic
reports and invoices prevented the government from verifying the work because
PROTEC did not submit the paper reports on time, follow the maintenance schedule,
or arrange all repairs through the COR or the fire inspector. For repairs in particular,
timely reports and invoices were necessary to verify the time and material charges.
Nor did government work certificate signature delays or supplier invoice delays
cause-let alone justify-the late unpaid invoice submissions. Because the
government properly refused to pay the unpaid invoices, the appeal is denied.

                                 FINDINGS OF FACT

I. Contract

       1. On December 20, 2013, the government awarded Contract No. W912CM-14-D-0008
(0008 Contract) to PROTEC for the maintenance and repair of electronic doors, gates,
scanners, sauna compact system and electric/hydraulic barriers, and bollards at U.S. Army
Garrison, Wiesbaden (R4, tab 3). The 0008 Contract consisted of two main types of
services-preventative maintenance and on-call emergency repairs (id. at 51-53).

      2. PROTEC had to submit a maintenance schedule within ten days of contract
award (R4, tab 3 at 54).

      3. Only the COR or the fire inspector could place an emergency repair call, to
which PROTEC had to respond within four hours (R4, tab 3 at 53).

       4. The 0008 Contract provided that the government would monitor PROTEC's
performance in accordance with a Quality Assurance Surveillance Plan (QASP) (R4,
tab 3 at 47). The QASP detailed the surveillance and evaluation of PROTEC's
performance (supp. R4, tab 204). Under the QASP, the government would document
deficient performance in non-conformance reports (NCRs) (id. at 4-6).

       5. The 0008 Contract required PROTEC to submit an electronic on-call
emergency report within two days of performing an emergency repair, and an
electronic condition report (collectively, reports) within seven days of performing
maintenance (R4, tab 3 at 54-55).

       6. The 0008 Contract also required PROTEC to "[ s ]ubmit invoices for the
previous month's contract services in Wide Area Work Flow (WA WF) for approval by
the COR No Later Than (NL T) the 10th working [day] of the next month." By stating
that invoices had to be for "the previous month's services," the 0008 Contract required


                                           2
that each invoice be for no more than one month's services. (R4, tab 3 at 30 (emphasis
added))

        7. The government would pay PROTEC for the maintenance on a fixed-price
basis, and for the repairs on a time-and-material basis (R4, tab 3 at 3-25, 47).

II.      Contract Administration

        A.    Maintenance Schedule and Emergency Calls

       8. In accordance with Performance Work Statement§ 5.7, PROTEC submitted a
proposed maintenance schedule on January 13, 2014, which the government approved
(app. supp. R4, tab 11).

        9. PROTEC did not follow the maintenance schedule, even before April 2016, 2
as the COR repeatedly informed PROTEC through NCRs (R4, tabs 22-24, 29, 34, 41,
44, 75, 97, 99, 125, 139, 156, 199, 199a; app. supp. R4, tabs 3d, 3s; tr. 1/95, 2/126-28).
In particular, at a February 10, 2016 performance meeting, the government faulted
PROTEC for not following the maintenance schedule. However, it also noted that the
schedule was not logical. 3 Therefore, the parties agreed that PROTEC would submit a
revised maintenance schedule (R4, tab 39 at 4; app. supp. R4, tab 343n).

        10. Melanie Brill-PROTEC's business manager-testified that PROTEC
notified the government weekly what work it would perform. However, she did not
testify for how long PROTEC provided those weekly notifications. (Tr. 1/122) As
documented in NCR 0016, PROTEC provided weekly schedules for a few weeks, but
then stopped (app. supp. R4, tab 3n at 17; tr. 2/206).

      11. On April 7, 2016, PROTEC submitted a proposed revised maintenance
schedule (R4, tab 55; app. supp. R4, tab 13).

       12. On May 2, 2016, the CO informed PROTEC that the proposed revised
maintenance schedule was unacceptable. The COR also certified that PROTEC had
not performed electrical work on schedule. (R4, tab 73) Indeed, PROTEC never
performed the electrical work (tr. 2/111 ).




2
    As discussed below, April 2016 is significant because PROTEC claims that the
        cause of schedule slippage was the government's delay in responding to an
        April 7, 2016 proposed revised maintenance schedule.
3
    The schedule was not logical because it called for maintenance of a climbing wall
        after the climbing season started (tr. 1/113-14 ).

                                            3
       13. On May 7, 2016, PROTEC responded to the CO, explaining that it was
unable to perform work according to the schedule due to its employee's injury (app.
supp. R4, tab 3n at 11 ).

        14. At a May 11, 2016 performance meeting, the government faulted PROTEC
for not following the schedule (R4, tab 76 at 2).

      15. On May I 7, 2016, PROTEC submitted a second revised proposed
maintenance schedule (R4, tab 84 at 1-2). The government did not approve that
schedule (tr. 1/131).

     16. On June 16, 2016, the CO added a comment to an NCR, indicating that
PROTEC still was not adhering to the revised schedule (app. supp. R4, tab 3n at 25).

       17. On September 8, 2016, the CO emailed PROTEC to inform it that the COR
had observed PROTEC employees performing unscheduled maintenance. PROTEC
responded that it had been unable to reach the COR by telephone to schedule the
maintenance. The CO responded that PROTEC was not authorized to perform
unscheduled maintenance without the COR's prior approval, and an unanswered
telephone call did not constitute prior approval. PROTEC agreed not to perform
unauthorized maintenance in the future. (R4, tab l 55e)

      18. The failure to follow the maintenance schedule prevented the government
from verifying that PROTEC had performed the maintenance properly (tr. 2/126-28).

     19. PROTEC responded to emergency calls from other individuals besides the
COR and the fire inspector (R4, tab 193 at 2).

       B.     Reports

      20. PROTEC did not submit electronic emergency repair reports within two
days of emergency services, or electronic condition reports within seven days of
maintenance (tr. 1/104-05). Rather, PROTEC documented its work by completing
paper work certificates (app. supp. R4, tab 6).

         21. However, as both the CO's testimony and the contemporaneous NCRs
establish, PROTEC did not submit the work certificates on time (i.e., within two or
seven days of the repairs or maintenance respectively) (R4, tabs 32-33, 39, 42, 76, 91,
95-95a, 97, 147a, 151, 190, 199c-d, 199f-h, 199j; app. supp. R4, tabs 3d-e, 3i-3j, 3p,
3r, 3t; tr. 2/126-27, 140-41, 143-44). In response to the NCRs, PROTEC did not
dispute that it submitted the reports late (app. supp. R4, tabs 3i-3j, 3p, 3r-3t). Indeed,
on September 12, 2016, PROTEC admitted that "most of [the Emergency Reports had]
not been sent within the contracted 2-day time frame" (app. supp. R4; tab 3i at 15).




                                            4
        22. The testimony of Jurgen Rinner-PROTEC's contract manager-further
confirms that PROTEC submitted work certificates for the unpaid work late.
Mr. Rinner testified that he would submit the work certificates to the COR, who would
sign the certificates within a day or two of performance (tr. 1/74, 92). Therefore, the
fact that almost none of the work certificates for the unpaid work contain the COR' s
signature demonstrates that Mr. Rinner did not obtain the COR's signature on those
work certificates by submitting them within a day or two of performance (app. supp.
R4, tabs 15-33).

        23. The late work certificates prevented the government from verifying that
PROTEC had performed the services properly (tr. 2/127-28, 140-41). In December 7.
2015 and September 20, 2016 letters, the CO notified PROTEC that it was not
submitting timely reports. The letters also stated that failure to submit timely reports
rendered it impossible to verify performance, and would result in non-payment of
invoices. (R4, tabs 26, 193)

       C.     Invoices

       24. Ms. Brill used the work certificates to generate invoices. Each invoice
covered multiple work certificates. The invoices included a cover sheet, which
indicated the date PROTEC created the invoice (tr. 1/133). The invoices also
might include supporting documents, such as work certificates and supplier invoices
(tr. 1/40, 116, 129, 133). The government did not pay nineteen of the invoices
(unpaid invoices) (app. supp. R4, tabs 15-33).

       25. For the unpaid invoices, as Table 1 shows, PROTEC did not submit the
invoices for the previous month's contracted services in WA WF within the tenth
working day of the next month. Rather, PROTEC was missing the submission deadline
by months and years. (App. supp. R4, tabs 15-33)




                                            5
                       TABLE 1: UNPAID INVOICE DELAYS

    Invoice #1 41 Date of Month(s) And Year(s) Of        Date          Date       Work
                    Last             Servicesl 5l       Invoice       Invoice     Cert.
                  Supplier                               Duel 61      Created
                  Invoice,
                   If Any
    100019/16 None         12/ 15 to 1/ 16             01/14/16       07/18/16 Yes
    100020/16 12/31/15 02/14, 01/15 to 04/15,          03/13/14       07/18/16 Yes
                                           7
                           06/15 to 12/15
    100030/16 03/28/15 01/16                           02/12/16       07/18/16 Yes
    100755/15 07/22/15 01/15 to 09/15                  02/13/15       07/18/16 Yes
    100806/15 08/31/15 01/15 to 02/15, 04/15 to        02/13/15       07/18/16 Yes
                           09/15
    100809/15 None         03/15                       04/14/15       07/18/16    Yes
    100810/15 None         03/15                       04/14/15       07/18/16    Yes
    301085/16 03/31/16 01/16 to 04/16                  02/12/16       07/18/16    Yes
    301223/16 None         01/15, 04/15, 06/15, 09/15, 02/13/15       07/18/16    Yes
                           ll/15tol2/15
    301283/16 9/08/15      03/15 to 04/15, 07/15 to    04/14/15       07/20/16 Yes
                           09/15
    301317/16 None         12/15                       01/14/16       07 /28/16   Yes
    301318/16 None         03/15                       04/14/15       08/15/16    No
    301369/16 None         03/15                       04/14/15       08/15/16    No
    301372/16 None         07/15, 09/15 to 11/15       08/14/15       08/16/16    No
    301376/16 None         03/14 to 04/14              04/14/14       08/17/16    No


4
    In this opinion, we omit the prefix "1000 l" from all invoice numbers.
5
    Where possible, we derive the "Month(s) And Year(s) of Services" from the work
         certificates. Where PROTEC did not attach work certificates, we use the dates
         PROTEC scheduled work, as reported in the worksheets attached to the invoice
         cover sheet.
6
    Because PROTEC was supposed to include only one month's services in an invoice,
         and the government could not partially pay an invoice, the "Date Invoice Due''
         column represents the tenth working day of the next month after the first month
         in which PROTEC provided billed-for services (R4, tab 3 at 30; tr. 2/50, 167).
7   The 100020/16 invoice included a work certificate dated November 27, 2016 (app.
         supp. R4, tab 25 at 55). That date clearly was a typographical error, as it was
         after the date PROTEC prepared the invoice on July 18, 2016 (id. at 1).
         Moreover, the receipt that follows that work certificate-which was dated
         November 24, 2015-shows that the work certificate date should have been
         November 27, 2015 (id. at 56).

                                            6
    301377/16   11/04/15   09/15 to    10/15             10/14/15     08/17/16   Yes
    301384/16   None       11/ 14 to   12/14             12/12/14     08/23/16   No
    301385/16   None       08/14 to    12/14             09/12/14     08/23/16   No
    301411/16   08/11/16   06/16 to    08/16             07 /14/16    09/14/16   Yes

(App. supp. R4, tabs 15-33)

       26. The government repeatedly notified PROTEC that it was submitting
invoices late, including in NCR 0012 (app. supp. R4, tab 3j; see also R4, tab 39 at 5).

        27. The late invoices prevented the government from verifying that PROTEC
had performed the services properly (tr. 2/167). Indeed, PROTEC acknowledged that
it was crucial for the government to receive a prompt invoice for repairs by conceding
that the COR could only verify the time and material charges with a tracked invoice
(tr. 1/116, 129).

       28. PROTEC does not dispute that it submitted the unpaid invoices late.
Rather, Ms. Brill testified that there were two reasons PROTEC submitted the unpaid
invoices late. (Tr. 1/119)

       29. First, Ms. Brill testified that PROTEC submitted the unpaid invoices late
because of delays receiving signed work certificates from the government (tr. 1/119).
However, in response to NCR 0012, PROTEC did not assert that it was submitting the
unpaid invoices late because of government work certificate signature delays (app.
supp. R4, tab 3j at 12). Further, PROTEC has not identified which specific unpaid
invoices government work certificate signature delays purportedly delayed. Nor has it
quantified how many days of delay the government work certificate signature delays
purportedly caused in each instance (id.). On the contrary, as Table 1 demonstrates,
many unpaid invoices 8 did not even include work certificates, making it impossible for
the government to track those invoices to the work (app. supp. R4, tabs 15-17, 21, 24,
28). For the remaining unpaid invoices, many supporting work certificates lacked
government signatures. Where there was a signature and a signature date, the
signature date was the service date, or shortly thereafter. Therefore, we find that
government work certificate signature delays did not cause the late unpaid invoice
submissions. (Id. tabs 18-20, 22-23, 25-27, 29-33)

     30. Second, Ms. Brill testified that PROTEC submitted the unpaid invoices late
because of delays receiving supporting supplier invoices (tr. 1/119). However,
PROTEC does not explain why the suppliers delayed submitting invoices (id.).


8
    In particular, Invoice Nos. 301318/16, 301369/16, 301372/16, 301376/16,
         301384/16, and 301385/16 did not include work certificates (app. supp. R4,
         tabs 15-33).

                                               7
Further, in response to NCR 0012, PROTEC did not assert that it was submitting the
unpaid invoices late because of supplier invoice delays (app. supp. R4, tab 3j at 13).
In any event, PROTEC has not identified which specific unpaid invoices the supplier
invoice delays purportedly delayed. Nor has PROTEC quantified how many days of
delay the supplier invoice delays purportedly caused in each instance (id.). On the
contrary, as Table 1 demonstrates, PROTEC did not even submit supplier invoices to
support 11 of the 19 unpaid invoices. 9 Moreover, PROTEC received the supplier
invoices for the remaining eight unpaid invoices at least a month-and up to a year-
before it created its invoice. Therefore, we find that supplier invoice delays did not
cause the late unpaid invoice submissions. (App. supp. R4, tabs 15-33)

III.    Procedural History

       3 1. On October 31, 2016, PROTEC submitted a certified claim for the unpaid
invoices (R4, tab 198).

        32. The CO issued a COFD denying the claim on February 28, 2017 (R4, tab 199
at 7-9).

        33. This appeal followed.

                                     DECISION

I. ·    The Government Properly Refused to Pay the Unpaid Invoices

       The government properly refused to pay the unpaid invoices because PROTEC
did not submit timely electronic reports or invoices. The government may refuse to
pay an invoice if a contractor does not deliver the services in accordance with the
contract requirements, or does not "properly and timely submit[] invoices for those
services." It is a contractor's burden to show that the nonpayment was improper.
Ahmed S. Al-Zhickrulla Est., ASBCA No. 52137, 03-2 BCA iJ 32,409 at 160,429-30.

      Here, PROTEC submitted electronic reports and invoices late. The 0008
Contract required PROTEC to submit electronic emergency repair reports within two
days of emergency repairs, and electronic condition reports within seven days of
maintenance (finding 5). It also required PROTEC to "[s]ubmit invoices for the
previous month's contract services in Wide Area Work Flow (WAWF) for approval by
the COR No Later Than (NLT) the 10th working [day] of the next month" (finding 6).
PROTEC did not submit an electronic emergency repair report within two days of


9
    In particular, PROTEC only supported Invoice Nos. 100020/16, 100030/16,
         100755/15, 100806/15, 301085/16, 301283/16, 301377/16, and 301411/16 with
         supplier invoices (app. supp. R4, tabs 15-33).

                                           8
each emergency repair, or an electronic condition report within seven days of each
maintenance, as required by the 0008 Contract (finding 20). Moreover, PROTEC did
not submit any of the unpaid invoices by the 10th working day of the next month after
the month in which PROTEC provided the billed-for services (finding 25). Indeed,
PROTEC was not a few days, or even weeks, late in submitting the unpaid invoices.
Rather, it was missing the submission deadlines by months and even over a year (id.).
Because PROTEC submitted electronic reports and invoices late, the government
properly refused to pay the unpaid invoices.

II.    PROTEC's Arguments to the Contrary are Meritless

        PROTEC argues that the late submissions of reports and invoices did not
prejudice the government. PROTEC also argues that the late submissions of invoices
in particular were excused. (App. br. at 47; app. reply br. at 38). As discussed below,
PROTEC has not met its burden of showing a lack of prejudice, or an excuse.

       A.    The Late Submissions of Reports and Invoices Prejudiced the
             Government

        PROTEC argues that the government suffered no prejudice from its late
submissions of electronic reports and invoices because timely paper work certificates,
the COR's awareness of the maintenance schedule, and the role of the COR and the
fire inspector in arranging emergency repairs permitted the COR to verify performance
(app. br. at 47; app. reply br. at 38). However, PROTEC has not met its burden of
showing a lack of prejudice.

       First, PROTEC has not shown that the work certificates permitted the COR to
verify performance because PROTEC did not submit timely paper work certificates to
the COR (finding 21 ). Indeed, many of the unpaid invoices lacked a work certificate
altogether, making it impossible for the government to track the invoice to the work
(findings, 25, 29).

        Second, PROTEC has not shown that awareness of the maintenance schedule
permitted the COR to verify the maintenance work because PROTEC did not follow
the schedule (finding 9). Without citing any evidence, PROTEC asserts that three of
the 19 unpaid invoices-namely Invoice Nos. 301318/16, 301369/16, and 301376/16-
involved electrical work that PROTEC performed on schedule (app. reply br. at 34).
However, as PROTEC concedes elsewhere (id. at 18), it did not perform the electrical
work on schedule (finding 12). Indeed, PROTEC never performed the electrical work
(id.). PROTEC also argues that it cannot be held responsible for the schedule slippage
because that slippage was due to the fact that it took the government approximately
three weeks-between April 7, 2016 and May 2, 2016-.to reject PROTEC's proposed



                                           9
"

    revised maintenance schedule (app. reply br. at 18, 192, at 32). 10 However, PROTEC
    was not following the schedule even before that period (finding 9). Indeed, almost
    none of the billed-for work in the unpaid invoices occurred between April 7, 2016 and
    May 2, 2016 (finding 25).

            Third, PROTEC has not shown that the COR and the fire inspector's role in
    arranging all emergency repairs permitted the COR to inspect the emergency repairs
    because the COR and the fire inspector did not make all the emergency repair
    appointments (finding 19). Moreover, as PROTEC acknowledges, it was crucial that it
    submit timely work certificates and invoices for repairs because tracked invoices were
    the only way the COR could substantiate the time and material charges (app. reply
    br. at 29-30; app. br. at 42; finding 27). Therefore, the late reports and invoices
    prejudiced the government by preventing it from verifying PROTEC's work and bills.

             B.    The Late Unpaid Invoice Submissions are not Excused

            PROTEC also argues that government work certificate signature delays and
    supplier invoice delays justified the late unpaid invoice submissions (app. br. at 47).
    However, PROTEC has not met its burden of showing that government work
    certificate signature delays and supplier invoice delays justified late unpaid invoice
    submissions.

            First, PROTEC has not shown that government work certificate signature
    delays justified the late unpaid invoice submissions. PROTEC did not assert in the
    contemporaneous documents that government work certificate signature delays caused
    the late unpaid invoice submissions (finding 29). Moreover, PROTEC has not
    identified which specific unpaid invoices government work certificate signature delays
    purportedly delayed (id.). Nor has it quantified how many days of delay the
    government work certificate signature delays purportedly caused (id.). On the
    contrary, the unpaid invoices show that many unpaid invoices did not even include
    work certificates (id.). Moreover, when the unpaid invoices included work
    certificates, many work certificates lacked government signatures (id.). Further, when
    the government signed and dated a work certificate, it did so on the service date, or
    shortly thereafter (id.). Such isolated cases of waiting a few days to receive a signed
    work certificate do not explain-let alone justify-the extensive delays in submitting
    the unpaid invoices (id.).

    10
         PROTEC also complains about the government's failure to tum over an internal
            memorandum regarding the February 10, 2016 performance meeting.
            However, PROTEC has not shown that that caused schedule slippage.
            PROTEC also argues that it provided weekly notices of the maintenance
            schedule. (App. br. at 45) However, it only provided those notices for a few
            weeks (finding 10).

                                                10
       Second, PROTEC has not shown that supplier invoice delays justified the late
invoice submissions. Delays by a supplier only excuse a contractor's delay if the
supplier's delays themselves are excusable. E&R Inc., ASBCA No. 48056, 95-2 BCA
127,745 at 138,338; Maeda Gumi, ASBCA No. 11122, 67-1BCA16144 at 28,487.
Here, PROTEC does not even attempt to show that any supplier invoice delays were
excusable (finding 30). Further, PROTEC did not assert in the contemporaneous
documents that supplier invoice delays caused the late unpaid invoice submissions
(id.). Moreover, PROTEC has not identified which specific unpaid invoices the
supplier invoice delays purportedly delayed (id.). Nor has it quantified how many
days of delay the supplier invoice delays purportedly caused (id.). On the contrary, the
unpaid invoices show that PROTEC did not even support most of the unpaid invoices
with supplier invoices (id.). For the unpaid invoices PROTEC supported with supplier
invoices, it received the supporting supplier invoices at least a month-and up to a
year-before it created each unpaid invoice (id.). Therefore, any supplier invoice
delays did not cause-let alone justify-the late unpaid invoice submissions (id.).

       In particular, PROTEC argues that one work certificate underlying Invoice
No. 100755/15 shows that PROTEC performed repairs on February 5, 2015 and
February 6, 2015, but did not receive a supplier invoice until six months later-on
July 21, 2015. However, PROTEC offers no explanation for the supplier's six-month
delay. (App. reply br. at 37-38) Moreover, instead of submitting its invoice by the
tenth business day of the next month after receiving that supplier invoice, PROTEC
waited about a year-until July 18, 2016-to submit Invoice No. 100755/15
(finding 25). Therefore, PROTEC's example only serves to highlight why any
supplier invoice delays did not cause-much less justify-the late unpaid invoice
submission.

                                   CONCLUSION

      This appeal is denied.

      Dated: May 15,2019



                                                  JAMESR. SWEET
                                                  Administrative Judge
                                                  Armed Services Board
                                                  of Contract Appeals

(Signatures continued)




                                           11
 l concur                                        I concur




 RICHARD SHACKLEFORD                             OWEN C. WILSON
 Administrative Judge                            Administrative Judge
 Acting Chairman                                 Vice Chairman
 Armed Services Board                            Armed Services Board
 of Contract Appeals                             of Contract Appeals



     I certify that the foregoing is a true copy of the Opinion and Decision of the
Armed Services Board of Contract Appeals in ASBCA No. 61185, Appeal of
PROTEC GmbH, rendered in conformance with the Board's Charter.

      Dated:



                                                 PAULLA K. GATES-LEWIS
                                                 Recorder, Armed Services
                                                 Board of Contract Appeals




                                           12
